{"id":3766,"date":"2017-12-08T14:56:46","date_gmt":"2017-12-08T13:56:46","guid":{"rendered":"https:\/\/breyer-rechtsanwaelte.de\/?p=3766"},"modified":"2024-09-24T11:38:51","modified_gmt":"2024-09-24T09:38:51","slug":"baurechtsticker-bgh-urteil-vom-26-10-2017-vii-zr-16-17-die-bauzeitforderung-entschaedigung-waehrend-annahmeverzug","status":"publish","type":"post","link":"https:\/\/breyer-rechtsanwaelte.de\/en\/baurechtsticker-bgh-urteil-vom-26-10-2017-vii-zr-16-17-die-bauzeitforderung-entschaedigung-waehrend-annahmeverzug\/","title":{"rendered":"Building law ticker: BGH, judgement of 26.10.2017, VII ZR 16\/17: The construction period claim - compensation during default of acceptance"},"content":{"rendered":"<div data-elementor-type=\"wp-post\" data-elementor-id=\"3766\" class=\"elementor elementor-3766\" data-elementor-post-type=\"post\">\n\t\t\t\t<div class=\"elementor-element elementor-element-3fa1aea e-con-full e-flex e-con e-parent\" data-id=\"3fa1aea\" data-element_type=\"container\" data-e-type=\"container\">\n\t\t\t\t<div class=\"elementor-element elementor-element-1d3e9b2 elementor-widget elementor-widget-text-editor\" data-id=\"1d3e9b2\" data-element_type=\"widget\" data-e-type=\"widget\" data-widget_type=\"text-editor.default\">\n\t\t\t\t\t\t\t\t\t<p><strong>Facts of the case:<\/strong><\/p>\t\t\t\t\t\t\t\t<\/div>\n\t\t\t\t<div class=\"elementor-element elementor-element-50a7cb9 elementor-widget elementor-widget-text-editor\" data-id=\"50a7cb9\" data-element_type=\"widget\" data-e-type=\"widget\" data-widget_type=\"text-editor.default\">\n\t\t\t\t\t\t\t\t\t<p>The client commissioned a specialist company to carry out sprinkler work. The parties included the VOB\/B (2006) in the contract. The contract provides for binding contractual deadlines for the completion of the respective construction phases. The last contract period ended in October 2010.<\/p>\t\t\t\t\t\t\t\t<\/div>\n\t\t\t\t<div class=\"elementor-element elementor-element-b6059a8 elementor-widget elementor-widget-text-editor\" data-id=\"b6059a8\" data-element_type=\"widget\" data-e-type=\"widget\" data-widget_type=\"text-editor.default\">\n\t\t\t\t\t\t\t\t\t<p>As the client did not fulfil its contractual obligations, the contractor was unable to meet the contractual deadlines. The contractor therefore had to continue its services into 2012. This is undisputed between the parties.<\/p>\t\t\t\t\t\t\t\t<\/div>\n\t\t\t\t<div class=\"elementor-element elementor-element-2d28715 elementor-widget elementor-widget-text-editor\" data-id=\"2d28715\" data-element_type=\"widget\" data-e-type=\"widget\" data-widget_type=\"text-editor.default\">\n\t\t\t\t\t\t\t\t\t<p>The contractor sued the client for reimbursement of increased labour and material costs that it had incurred as a result of not being able to perform parts of the services until after the end of the contract in 2011.<\/p>\t\t\t\t\t\t\t\t<\/div>\n\t\t\t\t<div class=\"elementor-element elementor-element-eb33e55 elementor-widget elementor-widget-text-editor\" data-id=\"eb33e55\" data-element_type=\"widget\" data-e-type=\"widget\" data-widget_type=\"text-editor.default\">\n\t\t\t\t\t\t\t\t\t<p>With success?<\/p>\t\t\t\t\t\t\t\t<\/div>\n\t\t\t\t<div class=\"elementor-element elementor-element-624dc69 elementor-widget elementor-widget-text-editor\" data-id=\"624dc69\" data-element_type=\"widget\" data-e-type=\"widget\" data-widget_type=\"text-editor.default\">\n\t\t\t\t\t\t\t\t\t<p><a href=\"http:\/\/breyer-rechtsanwaelte.de\/wp-content\/uploads\/2017\/12\/Breyer_Baurechtsticker1.pdf\" target=\"_blank\" rel=\"noopener\">Continue reading here.<\/a><\/p>\t\t\t\t\t\t\t\t<\/div>\n\t\t\t\t<\/div>\n\t\t\t\t<\/div>","protected":false},"excerpt":{"rendered":"<p>Note from lawyer Annika K\u00fchne, Frankfurt am Main<\/p>","protected":false},"author":1,"featured_media":8023,"comment_status":"closed","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"_acf_changed":false,"footnotes":""},"categories":[31,32],"tags":[],"class_list":["post-3766","post","type-post","status-publish","format-standard","has-post-thumbnail","hentry","category-aktuelles","category-baurechtsticker"],"acf":[],"_links":{"self":[{"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/posts\/3766","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/comments?post=3766"}],"version-history":[{"count":0,"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/posts\/3766\/revisions"}],"wp:featuredmedia":[{"embeddable":true,"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/media\/8023"}],"wp:attachment":[{"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/media?parent=3766"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/categories?post=3766"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/breyer-rechtsanwaelte.de\/en\/wp-json\/wp\/v2\/tags?post=3766"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}